FIDIC 設(shè)計(jì)采購施工合同條件（銀皮書第1條中英文）
                     FIDIC CONTRACT OF DESIGN, PURCHASE AND CONSTRUCTION
         （EPC）交鑰匙項(xiàng)目合同條件
 
Contents   目錄
 
1 General Provisions一般規(guī)定
1.2 Interpretation解釋
1.3 Communications通信交流
1.4 Law and Language法律和語言
1.5 Priority of Document 文件優(yōu)先次序
1.6 Contract Agreement合同協(xié)議書
1.7 Assignment權(quán)益轉(zhuǎn)讓
1.8 Care and Supply of Documents文件的照管和提供
1.9 Confidentiality保密性
1.10 Employer’s Use of Contractor’s Documents雇主使用承包商文件
1.11 Contractor’s Use of Employer’s Documents承包商使用雇主文件
1.12 Confidential Details保密事項(xiàng)
1.13 Compliance with Laws遵守法律
1.14 Joint and Several Liability共同的和各自的責(zé)任
2 The Employer雇主
2.1 Right of Access to the Site現(xiàn)場進(jìn)入權(quán)
2.2 Permits, Licences or Approves許可、執(zhí)照或批準(zhǔn)
2.3 Employer’s personnel雇主人員
2.4 Employer’s Financial Arrangements雇主的資金安排
2.5 Employer’s Claims雇主的索賠
  3 The Employer’s Administration雇主的管理
3.1 The Employer’s Representative雇主代表
3.2 The Employer’s personnel其他雇主人員
3.3 Delegated Persons受托人員
3.4 Instructions指示
3.5 Determinations確定
4 The Contractor承包商
4.1 The Contractor’s General Obligations承包商的一般義務(wù)
4.2 Performance security履約擔(dān)保
4.3 Contractor’s Representative承包商代表
4.4 subContractors分包商
4.5 Nominated Subcontractors指定的分包商
4.6 Co-operation合作
4.7 Setting out放線
4.8 Safety procedures安全程序
4.9 Quality Assurance質(zhì)量保證
4.10 Site Data現(xiàn)場數(shù)據(jù)
4.11 Suffciency of the Contract Pric合同價(jià)格
4.12 Unforeseeable Difficulties不可預(yù)見的困難
4.13 Rights of way and Facilities道路通行權(quán)與設(shè)施
4.14 Avoidance of Interference避免干擾
4.15 Access Route進(jìn)場通路
4.16 Transport of Goods貨物運(yùn)輸
 
4.17 Contractor’s Equipment承包商設(shè)備
4.18 Protection of the Environment環(huán)境保護(hù)
4.19 Electricity, Water and Gas電、水和燃?xì)?/a>
4.20 Employer’s Equipment and Free-Issue Material雇主設(shè)備和免費(fèi)供應(yīng)的材料
4.21 Progress Reports進(jìn)度報(bào)告
4.22 Security of the Site現(xiàn)場保安
4.23 Contractor’s Operations on Site承包商的現(xiàn)場作業(yè)
4.24 Fossils化石
5 Design設(shè)計(jì)
5.1 General Design Obligations設(shè)計(jì)義務(wù)一般要求
5.2 Contractor’s Document承包商文件
5.3 Contractor’s Undertaking承包商的承諾
5.4 Technical Standards and Regulations技術(shù)標(biāo)準(zhǔn)和法規(guī)
5.5 Training培訓(xùn)
5.6 As-Built Documents竣工文件
5.7 Operation and Maintenance Manuals操作和維修手冊
5.8 design Error設(shè)計(jì)錯(cuò)誤
6 Staff and Labour員工
6.1 Engagement of Staff and Labour員工的雇用
6.2 Rates of Wages and Conditions of Labour工資標(biāo)準(zhǔn)和勞動條件
6.3 Persons in the Service of Employer為雇主服務(wù)的人員
6.4 Labour Laws勞動法
6.5 Working Hours工作時(shí)間
6.6 Facilities for Staff and Labour為員工提供設(shè)施
6.7 Health and Safety健康和安全
6.8Contractor’s Superintendence承包商的監(jiān)督
6.9Contractor’s Personnel承包商人員
6.10 Records of contractor’s Personnel and Equipment承包商人員和設(shè)備的記錄
6.11 Disorderly Conduct無序行為
7 Plant, Materials and Workmanship生產(chǎn)設(shè)備、材料和工藝
7.1 Manner of Execution實(shí)施方法
7.2 Samples樣品
7.3 Inspection檢驗(yàn)
7.4 Testing試驗(yàn)
7.5 Rejection拒收
7.6 Remedial Work修補(bǔ)工作
7.7 Ownership of Plant and Materials生產(chǎn)設(shè)備和材料的所有權(quán)
7.8 Royalties土地(礦區(qū))使用費(fèi)
8 Commencement, Delays and Suspension開工、延誤和暫停
8.1 Commencement of Works工程的開工
8.2 Time for Completion竣工時(shí)間
8.3 Programme進(jìn)度計(jì)劃
8.4 Extension of Time for Completion竣工時(shí)間延長
8.5 Delays Caused by Authorities當(dāng)局造成的延誤
8.6 Rate of Progress工程進(jìn)度
8.7 Delay Damages誤期損害賠償費(fèi)
8.8 Suspension of Work暫時(shí)停工
8.9 Consequences of Suspension暫停的后果
8.10 Payment for Plant and Materials in Event of Suspension暫停時(shí)對生產(chǎn)設(shè)備和材料的付款
8.11 Prolonged Suspension延長暫停
8.12 Resumption of Work復(fù)工
9 Tests on Completion竣工試驗(yàn)
9.1 Contractor’s Obligations承包商的義務(wù)
9.2 Delayed Tests延誤的試驗(yàn)
9.3 Retesting重新試驗(yàn)
9.4 Failure to Pass Tests on Completion未能通過竣工試驗(yàn)
10 Employer’s Taking Over雇主的接收
10.1 Taking Over of the Works and Sections工程和分項(xiàng)工程的接收
10.2 Taking Over of Parts of the Works部分工程的接收
10.3 Interference with Tests on Completion對竣工試驗(yàn)的干擾
11 Defects Liability缺陷責(zé)任
11.1 Completion of Outstanding Work and Remedying Defects完成掃尾工作和修補(bǔ)缺陷
11.2 Cost of Remedying Defects修補(bǔ)缺陷的費(fèi)用
11.3 Extension of Defects Notification Period缺陷通知期的延長
11.4 Failure to Remedy Defects未能修補(bǔ)的缺陷
11.5 Removal of Defective Work移出有缺陷的工程
11.6 Further Tests進(jìn)一步試驗(yàn)
11.7 Right of Access進(jìn)入權(quán)
11.8 Contractor to Search承包商調(diào)查
11.9 Performance Certificate履約證書
11.10 Unfulfilled Obligations未履行的義務(wù)
11.11 Clearance of Site現(xiàn)場清理
12 Tests after Completion竣工后試驗(yàn)
12.1 Procedure for Tests after Completion竣工后試驗(yàn)的程序
12.2Delayed Tests延誤的試驗(yàn)
12.3 Retesting重新試驗(yàn)
12.4 Failure to Pass Tests after Completion未能通過的竣工后試驗(yàn)
13 Variations and Adjustments變更和調(diào)整
13.1 Right to Vary變更權(quán)
13.2 Value Engineering價(jià)值工程
13.3 Variation Procedure變更程序
13.4 Payment in Applicable Currencies以適用貨幣支付
13.5 provisional Sums暫列金額
13.6 Daywork計(jì)日工作
13.7 Adjustments for Changes in Legislation因法律改變的調(diào)整
13.8 Adjustments for Changes in Cost因成本改變的調(diào)整
14 Contract price and Payment合同價(jià)格和付款
14.1 The Contract Price合同價(jià)格
14.2 Advance payment預(yù)付款
14.3 Application for Interim Payments期中付款的申請
14.4 Schedule of Payments付款價(jià)格表
14.5 Plant and Materials intended for the Works擬用于工程的生產(chǎn)設(shè)備和材料
14.6 Interim Payments期中付款
14.7 Timing of Payments付款的時(shí)間安排
14.8 Delayed Payment延誤的付款
14.9 Payment of Retention Money保留金支付
14.10 Statement at Completion施工報(bào)表
14.11 Application for Final Payment最終付款的申請
14.12 Discharge結(jié)清證明
14.13 Final Payment最終付款
14.14 Cessation of Employer’s Liability雇主責(zé)任的中止
14.15 Currencies of Payment支付的貨幣
15 Termination by Employer由雇主終止
15.1 Notice to Correct通知改正
15.2 Termination by Employer由雇主終止
15.3 Valuation at Date of Termination終止日期時(shí)的估價(jià)
15.4 Payment after Termination終止后的付款
15.5 Employer’s Entitlement to Termination雇主終止的權(quán)利
16 Suspension and termination by Contractor由承包商暫停和終止
16.1 Contractor’s Entitlement to Suspend Work承包商暫停工作的權(quán)利
16.2 Termination by Contractor由承包商終止
16.3 Cessation of Work and Removal of Contractor’s Equipment停止工作和承包商設(shè)備的撤離
16.4 Payment on Termination終止時(shí)的付款
17 Risk and Responsibility風(fēng)險(xiǎn)與職責(zé)
17.1 Indemnities保障
17.2 Contractor’s Care of the Works承包商對工程的照管
17.3 Employer’s Risks雇主的風(fēng)險(xiǎn)
17.4 Consequence of Employer’s Risks雇主風(fēng)險(xiǎn)的后果
17.5 Intellectual and Industrial Property Rights知識產(chǎn)權(quán)和工業(yè)產(chǎn)權(quán)
17.6 Limitation of Liability責(zé)任限度
18 Insurance保險(xiǎn)
18.1 General Requirements for Insurances有關(guān)保險(xiǎn)的一般要求
18.2 Insurance for Works and Contractor’s Equipment工程和承包商設(shè)備的保險(xiǎn)
18.3 Insurance against Injury to Persons and Damage to Property  人身傷害和財(cái)產(chǎn)損害險(xiǎn)               
18.4 Insurance for Contractor’s Personnel承包商人員的保險(xiǎn)
19 Force Majeure不可抗力
19.1 Definition of Force Majeure不可抗力的定義
19.2 Notice of Force Majeure不可抗力的通知
19.3 Duty to Minimise Delay將延誤減至最小的義務(wù)
19.4 Consequences of Force Majeure不可抗力的后果
19.5 Force Majeure Affecting Subcontractor不可抗力影響分包商
19.6 Optional Termination, Payment and Release自主選擇終止、支付和解除
19.7 Release from Performance under the Law根據(jù)法律解除履約
20 Claims, Disputes and Arbitration索賠、爭端和仲裁
20.1 Contractor’s Claims承包商的索賠
20.2 Appointment of the Dispute Adjudication Board爭端裁決委員會的任命
20.3 Failure to Agreement Dispute Adjudication Board對爭端裁決委員會未能取得一致時(shí)
20.4 Obtaining Dispute Adjudication Board’s Decision取得爭端裁決委員會的決定
20.5 Amicable Settlement友好解決
20.6 Arbitration仲裁
20.7 Failure to Comply with Dispute Adjudication Board’s ecision未能遵守爭端裁決委員會的決定
20.8 Expiry of Dispute Adjudication Board’s Appointment爭端裁決委員會任命期滿
 

1 General Provisions一般規(guī)定
1.1Definitions   定義
In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise.
在合同條件（“本條件”），包括專用條件和通用條件中，下列詞語和措辭應(yīng)具   有以下所述的含義.除上下文另有要求外，文中人員或當(dāng)事各方等詞語包括公司和其他合法實(shí)體.
1.1.1The Contract  合同
1.1.1.1 “Contract” means the Contract Agreement, these Conditions, the Employer’s Requirement, the Tender, and further document (if any) which are listed in the Contract Agreement.
 “合同”系指合同協(xié)議書、本條件、雇主要求、投標(biāo)書和合同協(xié)議書列出的其他文件（如果有）.
1.1.1.2 “Contract Agreement” means the contract agreement referred to in Sub-Clause 1.6 [Contract Agreement], including any annexed memoranda
“合同協(xié)議書”系指第1.6款[合同協(xié)議書]中所述的合同協(xié)議書及所附各               項(xiàng)備忘錄.
1.1.1.3 “Employer’s requirements” means the document entitled employer’s requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.
“雇主要求”系指合同中包括的，題為雇主要求的文件，其中列明工程的目標(biāo)、范圍、和（或）設(shè)計(jì)和（或）其他技術(shù)標(biāo)準(zhǔn)，以及按合同對此項(xiàng)文件所作的任何補(bǔ)充和修改.
1.1.1.4 “Tender” means the Contractor’s signed offer for the Works and all other documents which the Contractor submitted therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract.
“投標(biāo)書”系指包含在合同中的由承包商提交的為完成工程簽署的報(bào)價(jià)，以及隨同提交的所有其他文件（本條件和雇主要求除外，如同時(shí)提交）.
 1.1.1.5 “Performance Guarantees” and “Schedule of payments” mean the documents so named (if any), as included in the Contract.
“履約保證”和“付款計(jì)劃表”系指合同中包括的具有上述名稱的文件（如果有）.
1.1.2 Parties and Persons各方和人員
1.1.2.1 “Party” means the Employer or the Contractor, as the context requires.
“當(dāng)事方（或一方）”根據(jù)上下文需要，或指雇主，或指承包商.
1.1.2.2 “Employer” means the person named as employer in the Contract Agreement and the legal successors in title to this person.
“雇主”系指在合同協(xié)議書中被稱為雇主的當(dāng)事人及其財(cái)產(chǎn)所有權(quán)的合法繼承人.
1.1.2.3 “Contractor” means the person(s) named as contractor in the Contract Agreement and the legal successors in title to this person(s).
“承包商”系指合同協(xié)議書中被稱為承包商的當(dāng)事人及其財(cái)產(chǎn)所有       權(quán)的合法繼承人.
1.1.2.4 “Employer’s Representative” means the person named by the Employer in the Contract or appointed from time to time by the Employer under Sub-Clause 3.1 [ the Employer’s Representative], who acts on behalf of the Employer.
“雇主代表”系指由雇主在合同中指名的人員，或有時(shí)由雇主根據(jù)第3.1款［雇主代表的人員］的規(guī)定任命為其代表的人員.
1.1.2.5 “Contractor’s Representative” means the person named by the Contractor in the Contract or appointed from time to time by the Contractor Sub-Clause 4.3 [the Contractor’s Representative], who acts on behalf of the Contractor.
“承包商代表”系指由承包商在合同中指名的人員，或有時(shí)由承包商根據(jù)第4.3款[承包商代表]的規(guī)定任命為其代表的人員.
1.1.2.6 “Employer’s Personnel” means the Employer’s   Representative, the assistants referred to in Sub-Clause 3.2 [Other Employer’s Personnel] and all other staff, labour and other employees of the Employer and of the Employer’s Representative; and any other personnel notified to the Contractor, by the Employer or the Employer’s Representative, as Employer’s Personnel. “雇主人員”系指雇主代表、第3.2款[其他雇主人員]中提到的助手、                    以及雇主和雇主代表的所有其他職員、工人和其他雇員，以及雇主或雇主代表通知承包商作為雇主人員的任何其他人員.
1.1.2.7 “Contractor’s Personnel” means the Contractor’s Representative and all personnel whom the Contractor utilizes on Site, who may include the staff, labour and other employees of the Contractor and of each Subcontractor, and any other personnel assisting the Contractor in the execution of the works.
 “承包商人員”系指承包商代表和承包商在現(xiàn)場聘用的所有人員，            包括承包商和每個(gè)分包商的職員、工人和其他雇員，以及所有其他幫助承包商實(shí)施工程的人員.
1.1.2.8 “Subcontractor” means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part of the Works; and the legal successors in title to each of these persons.
 “分包商”系指為完成部分工程，在合同中指名為分包商、或被任命為分包商的任何人員，以及這些人員財(cái)產(chǎn)所有權(quán)的合法繼承人.
1.1.2.9 “DAB” means the person or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 [Appointment of the Dispute Adjudication Board] or Sub-Clause 20.3 [Failure to Agree Dispute Adjudication Board].
  “DAB（爭端裁決委員會）”系指在合同中如此指名的一名或三名人員，或根據(jù)第20.2款[爭端裁決委員會的任命]或第20.3款[對爭端裁決委員會未能取得一致]的規(guī)定任命的其他人員.
1.1.2.10 “FIDIC” means the Federation International des Ingenieurs-Conseils, the international federation of consulting engineers.
 “菲迪克（FIDIC）”系指國際咨詢工程師聯(lián)合會.
1.1.3         Dates ,Test, Periods and Completion日期、試驗(yàn)、期限和竣工                        1.1.3.1 “Base Date” means the date 28 days prior to the latest date            for submission of the Tender.
 “基準(zhǔn)日期”系指遞交投標(biāo)書截止前28天的日期.
1.1.3.2 “Commencement Date” means the date notified under                               Sub-Clause 8.1 [Commencement of Works], unless otherwise defined in the Contract Agreement.
“開工日期”系指根據(jù)第8.1款[工程的開工]的規(guī)定通知的日期，合同協(xié)議書中另有規(guī)定的除外.
1.1.3.3 “Time for Completion” means the time for completing the                 Works or a Section (as the case may be) under Sub-Clause 8.2 [Time for Completion], as stated in the Particular Conditions (with any extension under Sub-Clause 8.4 [Execution of Time for Completion]), calculated from the Commencement Date.
“竣工時(shí)間”系指專用條件中規(guī)定的，自開工日期算起，至工程或某分項(xiàng)工程（視情況而定）根據(jù)第8.2款[竣工時(shí)間]規(guī)定的要求竣工（連同根據(jù)第8.4款[竣工時(shí)間的延長]的規(guī)定提出的任何延長期）的全部時(shí)間.
1.1.3.4 “Tests on Completion” means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the works or a Section (as the case may be) are taken over by the Employer.
“竣工試驗(yàn)”系指在合同中規(guī)定或雙方商定的，或按指示作為一項(xiàng)變更的，在工程或某分項(xiàng)工程（視情況而定）被雇主接收前，根據(jù)第9條[竣工試驗(yàn)]的要求，進(jìn)行的試驗(yàn).
1.1.3.5 “Taking-Over Certificate” means a certificate issued under Clause 10 [Employer’s Taking Over].
“接收證書”系指根據(jù)第10條[雇主接收]的規(guī)定頒發(fā)的證書.
1.1.3.6 “Tests after Completion” means the tests (if any) are specified in    the Contract and which are carried out under Clause 12 [Tests after Completion] after the works or a Section (as the case may be) are taken over by the Employer.
 “竣工后試驗(yàn)”系指在合同中規(guī)定的，在工程或某分項(xiàng)工程（視情況而定）被雇主接收后，根據(jù)第12條[竣工后試驗(yàn)]的要求，進(jìn)行的試驗(yàn)（如果有）.
1.1.3.7 “Defects Notification Period” means the period for notifying defects in the Works or a Section (as the case may be) under Sub-Clause 11.1 [Completion of Understanding Works and Remedying Defects], as stated in the Particular Conditions (with any extension under Sub-Clause 11.3 [Extension of Defects Notification Period]), calculated from the date on which the Works or Section is competed as certified under Sub-Clause 10.1 [Taking Over of the Works and Sections]. If no such period is stated in the Particular Conditions, the period shall be one year.
  “缺陷通知期限”系指專用條件中規(guī)定的，自工程或某分項(xiàng)工程（視情況而定）根據(jù)第10.1款[工程和分項(xiàng)工程的接收]的規(guī)定證明的竣工日期算起，至根據(jù)第11.1款[完成掃尾工作和修補(bǔ)缺陷]的規(guī)定通知工程或分項(xiàng)工程存在缺陷的期限（連同根據(jù)第11.3款[缺陷通知期限的延長]的規(guī)定提出的任何延長期）.如果專用條件中沒有提出這一期限，該期限應(yīng)為一年.
 1.1.3.8 “Performance Certificate” means the certificate issued under     Sub-Clause 11.9 [Performance Certificate].
 “履約證書”系指根據(jù)第11.9款[履約證書]的規(guī)定頒發(fā)的證書.
1.1.3.9     “day” means a calendar day and “year” means 365 days.
   “日（天）”系指一個(gè)日歷日，“年”系指365天.
1.1.4            Money and Payments   款項(xiàng)與付款
1.1.4.1          “Contract Price” means the agreed amount stated in the Contract Agreement for the design, execution and completion of the Works and the remedying of any defects, and includes adjustment (if any) in accordance with the contract.
       “合同價(jià)格”系指在合同協(xié)議書中寫明的、經(jīng)商定的工程設(shè)計(jì)、施工、竣工和缺陷修補(bǔ)的款額，包括以及按照合同做出的調(diào)整（如果有）.
1.1.4.2           “Cost” means all expenditure reasonably incurred (or to be incurred) by the Contractor, whether on or off the Site, including overhead and similar charges, but does not include profit.
      “成本（費(fèi)用）”系指承包商在現(xiàn)場內(nèi)外所發(fā)生（或?qū)�發(fā)生）的所          有合理開支，包括管理費(fèi)用及類似的支出，但不包括利潤.
1.1.4.3           “Final Statement” means the statement defined in Sub-Clause 14.11[Application for Final Payment].
       “最終報(bào)表”系指第14.11款[最終付款的申請]規(guī)定的報(bào)表.
1.1.4.4           “Foreign Currency” means a currency in which part (or all) of the Contract Price is payable, but not the Local Currency
         “外幣”系指可用于支付合同價(jià)格中部分（或全部）款項(xiàng)的當(dāng)?shù)刎泿乓酝獾哪撤N貨幣.
1.1.4.5           “Local Currency” means the currency of the Country.
       “當(dāng)?shù)刎泿?rdquo;系指工程所在國的貨幣.
1.1.4.6            “Provisional Sum” means a sum (if any) which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Material or services under Sub-Clause 13.5 [Provisional Sums]
       “暫列金額”系指合同中規(guī)定作為暫列金額的一筆款額（如果有），根據(jù)第13.5款[暫列金額]的規(guī)定，用于工程某一部分的實(shí)施，或用于提供生產(chǎn)設(shè)備、材料或服務(wù).
1.1.4.7            “Retention Money” means the accumulated retention moneys which the Employer retains under Sub-Clause 14.3 [Application for Interim Payments] and pays under Sub-Clause 14.9 [Payment of Retention Money].
      “保留金”系指雇主根據(jù)第14.3款[期中付款的申請]的規(guī)定扣留的保留金累計(jì)金額，根據(jù)第14.9款[保留金的支付]的規(guī)定進(jìn)行支付.
1.1.4.8     “Statement” means a statement submitted by the Contractor as part of an application for payment under Clause 14 [Contract Price and Payment].
      “報(bào)表”系指承包商根據(jù)第14條[合同價(jià)格和付款]的規(guī)定提交的作為付款申請的組成部分的報(bào)表.
1.1.5        Works and Goods工程和貨物
1.1.5.1    “Contractor’s Equipment” means all apparatus, machinery,   vehicles and other things required for the execution and completion of the Works and remedying of any defects. However, Contractor’s Equipment excludes Temporary Works, Employer’s Equipment (if any), Plant, Materials and any other things intended to form or forming part of the Permanent Works.
       “承包商設(shè)備”系指為實(shí)施和完成工程、以及修補(bǔ)任何缺陷需要的所有儀器、機(jī)械、車輛和其他物品.但承包商設(shè)備不包括臨時(shí)工程、雇主設(shè)備（如果有）、以及擬構(gòu)成或正構(gòu)成永久工程一部分的生產(chǎn)設(shè)備、材料和其他任何物品.
1.1.5.2     “Goods” means Contractor’s Equipment, Materials, Plant and Temporary Works, or any of them as appropriate.
        “貨物”系指承包商設(shè)備、材料、生產(chǎn)設(shè)備和臨時(shí)工程，或視情況其中任何一種.
1.1.5.3     “Materials” means things of all kinds (other than Plant) intended to form or forming part of the Permanent Works, including the supply-only materials (if any) to be supplied by the Contractor under the Contract.
      “材料”系指擬構(gòu)成或正構(gòu)成永久工程一部分的各類物品（生產(chǎn)設(shè)備除外），包括根據(jù)合同要由承包商供應(yīng)的只供材料（如果有）.
1.1.5.4     “Permanent Works” means the permanent works to be designed and executed by the Contractor under the Contract.
       “永久工程”系指根據(jù)合同承包商要進(jìn)行設(shè)計(jì)和施工的永久性工程.
1.1.5.5     “Plant “means the apparatus, machinery and vehicles intended to form or forming part of the Permanent Works.
      “生產(chǎn)設(shè)備”系指擬構(gòu)成或正構(gòu)成永久工程一部分的儀器、機(jī)械和車輛.
1.1.5.6     “Section” means a part of the Works specified in the Particular Conditions as a Section (if any).
      “分項(xiàng)工程”系指在專用條件中確定為分項(xiàng)工程（如果有）的工程組成部分.
1.1.5.7     “Temporary Works” means all temporary works of every kind (other than Contractor’s Equipment) required on Site for the execution and completion of the Permanent Works and the remedying of any defects.
       “臨時(shí)工程”系指為實(shí)施和完成永久工程及修補(bǔ)任何缺陷，在現(xiàn)場所需的所有各類臨時(shí)性工程（承包商設(shè)備除外).
1.1.5.8     “Works” means the Permanent Works and the Temporary Works, or either of them as appropriate.
“工程”系指永久工程和臨時(shí)工程，或視情況指二者之一.